2307. SUSPENSION OF WORK

2307 SUSPENSION OF WORK 2307.1 Suspension of work under a construction or architect-engineer contract may be ordered by the contracting officer for a reasonable period of time. 2307.2 If the contractor believes that the suspension is unreasonable, the contractor may submit a written claim for increases in the cost of performance due to the suspension, excluding profit, in accordance with the provisions of Chapter 38 of this title. SOURCE: Final Rulemaking published at 35 DCR 1551 (February 26, 1988).