VA contract clauses for non-commercial purchases.

(a)(1) Insert the clause at 852.232-70, Payments Under Fixed-Price Construction Contracts (Without NAS-CPM) in solicitations and contracts that contain the FAR clause at 52.232-5, Payments Under Fixed-Price Construction Contracts, and if the solicitation or contract does not require use of the “Network Analysis System—Critical Path Method (NAS-CPM).” (2) If the solicitation or contract includes guarantee period services, the contracting officer shall use the clause with its Alternate I. (b)(1) Insert the clause at 852.232-71, Payments Under Fixed-Price Construction Contracts (Including NAS-CPM), in solicitations and contracts that contain the FAR clause at 52.232-5, Payments Under Fixed-Price Construction Contracts, and if the solicitation or contract requires use of the “Network Analysis System—Critical Path Method (NAS-CPM).” (2) If the solicitation or contract includes guarantee period services, the contracting officer shall use the clause with its Alternate I. [83 FR 49306, Oct. 1, 2018]